1. Beschaffer
1.1.
Beschaffer
Offizielle Bezeichnung: Bus Eireann/Irish Bus
Rechtsform des Erwerbers: Organisation, die einen durch eine zentrale Regierungsbehörde subventionierten Auftrag vergibt
Tätigkeit des öffentlichen Auftraggebers: Allgemeine öffentliche Verwaltung
Tätigkeit des Auftraggebers: Städtische Eisenbahn-, Straßenbahn-, Oberleitungsbus- oder Busdienste
2. Verfahren
2.1.
Verfahren
Titel: Qualification Panel for Supply Installation and Commissioning of Electric Vehicle Chargers to Regional City and Towns - Amended.
Beschreibung: This is a readvertisement and no action is required if already a prequalified panelist. The Contracting Authority proposes creation of a qualification panel for the Supply, Installation and Annual Maintenance of EV Chargers for Buses. During the Term, when a requirement arises under this procurement process, suppliers on the Qualification Panels who have been deemed suitably qualified may be invited to submit a tender for such requirements. Each tender process conducted off this qualification panel will require a turnkey solution for the supply and installation of electric vehicle charging infrastructure for optimal charging of future electric buses. The scope of works includes complete project management of the turnkey solution, the associated electrical and civil works required for the safe installation and commissioning of all related equipment, including (but not limited to) transformers, chargers and charging points at the site and the back-office support protocols and training of relevant Bus Éireann staff. The scope includes provision of suitable energy storage systems or other sustainable backup systems in the event of loss of grid power supply. The scope also includes providing these services and products on a novated basis to a lead contractor, appointed by Bus Éireann, for larger depot construction projects. A comprehensive Service and Maintenance support package will also be required for a period of not less than 5 years. Tenders within the qualification framework duration will be specified to reflect the needs of the particular location and fleet provided. They will also reflect developments in charging technology, opportunity charging and new products over the duration of the qualification period. Site installation and commissioning of the charging infrastructure is expected to be completed in line with projected rollout planning. The complete turnkey solution shall be compliant with all relevant Irish and European statutory regulations and international standards governing the installation and use of such equipment and will be based on: • 150kW IEC 61851 Mode 4 Direct Current charging protocol, using a Combined Charging System 2.0 (CCS 2.0) Combo 2 charging connection. • 3 phase DC EV Charger - 120kW – 180kW IEC 61851 Mode 4 Direct Current charging protocol, dual outlet using a Combined Charging System 2.0 (CCS 2.0) Combo 2 charging connection. • 3 phase DC EV Charger - 30kW – 60kW IEC 61851 Mode 4 Direct Current charging protocol, using a Combined Charging System 2.0 (CCS 2.0) Combo 2 charging connection. • 3 phase AC EV Charger – 22kW IEC 61851 Mode 3 Alternating Current charging protocol, dual outlet using a Type 2 to Type 2 EV charging cable. • 1 phase AC EV Charger – 22kW IEC 61851 Mode 3 Alternating Current charging protocol, dual outlet using a Type 2 to Type 2 EV charging cable. • 1 phase AC EV Charger – 7kW IEC 61851 Mode 3 Alternating Current charging protocol, using a Type 2 to Type 2 EV charging cable
Kennung des Verfahrens: e0ddc822-8113-4245-b743-269f76936a8c
Verfahrensart: Nichtoffenes Verfahren
2.1.1.
Zweck
Art des Auftrags: Bauleistungen
Haupteinstufung (cpv): 45310000 Installation von elektrischen Leitungen
Zusätzliche Einstufung (cpv): 45317000 Sonstige Elektroinstallationsarbeiten, 45000000 Bauarbeiten, 31158000 Ladegeräte, 31158100 Batterieladegeräte, 31158200 Auflader, 31681500 Aufladegeräte, 34144900 Elektrofahrzeuge, 34144910 Elektrobusse
2.1.2.
Erfüllungsort
Stadt: Dublin
Land, Gliederung (NUTS): Dublin (IE061)
Land: Irland
2.1.4.
Allgemeine Informationen
Rechtsgrundlage:
Richtlinie 2014/25/EU
2.1.6.
Ausschlussgründe
Quellen der Ausschlussgründe: Auftragsunterlagen
5. Los
5.1.
Los: LOT-0001
Titel: Qualification Panel for Supply Installation and Commissioning of Electric Vehicle Chargers to Regional City and Towns - Amended.
Beschreibung: This is a readvertisement and no action is required if already a prequalified panelist. The Contracting Authority proposes creation of a qualification panel for the Supply, Installation and Annual Maintenance of EV Chargers for Buses. During the Term, when a requirement arises under this procurement process, suppliers on the Qualification Panels who have been deemed suitably qualified may be invited to submit a tender for such requirements. Each tender process conducted off this qualification panel will require a turnkey solution for the supply and installation of electric vehicle charging infrastructure for optimal charging of future electric buses. The scope of works includes complete project management of the turnkey solution, the associated electrical and civil works required for the safe installation and commissioning of all related equipment, including (but not limited to) transformers, chargers and charging points at the site and the back-office support protocols and training of relevant Bus Éireann staff. The scope includes provision of suitable energy storage systems or other sustainable backup systems in the event of loss of grid power supply. The scope also includes providing these services and products on a novated basis to a lead contractor, appointed by Bus Éireann, for larger depot construction projects. A comprehensive Service and Maintenance support package will also be required for a period of not less than 5 years. Tenders within the qualification framework duration will be specified to reflect the needs of the particular location and fleet provided. They will also reflect developments in charging technology, opportunity charging and new products over the duration of the qualification period. Site installation and commissioning of the charging infrastructure is expected to be completed in line with projected rollout planning. The complete turnkey solution shall be compliant with all relevant Irish and European statutory regulations and international standards governing the installation and use of such equipment and will be based on: • 150kW IEC 61851 Mode 4 Direct Current charging protocol, using a Combined Charging System 2.0 (CCS 2.0) Combo 2 charging connection. • 3 phase DC EV Charger - 120kW – 180kW IEC 61851 Mode 4 Direct Current charging protocol, dual outlet using a Combined Charging System 2.0 (CCS 2.0) Combo 2 charging connection. • 3 phase DC EV Charger - 30kW – 60kW IEC 61851 Mode 4 Direct Current charging protocol, using a Combined Charging System 2.0 (CCS 2.0) Combo 2 charging connection. • 3 phase AC EV Charger – 22kW IEC 61851 Mode 3 Alternating Current charging protocol, dual outlet using a Type 2 to Type 2 EV charging cable. • 1 phase AC EV Charger – 22kW IEC 61851 Mode 3 Alternating Current charging protocol, dual outlet using a Type 2 to Type 2 EV charging cable. • 1 phase AC EV Charger – 7kW IEC 61851 Mode 3 Alternating Current charging protocol, using a Type 2 to Type 2 EV charging cable
Interne Kennung: 0
5.1.1.
Zweck
Art des Auftrags: Bauleistungen
Haupteinstufung (cpv): 45310000 Installation von elektrischen Leitungen
Zusätzliche Einstufung (cpv): 45317000 Sonstige Elektroinstallationsarbeiten, 45000000 Bauarbeiten, 31158000 Ladegeräte, 31158100 Batterieladegeräte, 31158200 Auflader, 31681500 Aufladegeräte, 34144900 Elektrofahrzeuge, 34144910 Elektrobusse
5.1.2.
Erfüllungsort
Land, Gliederung (NUTS): Dublin (IE061)
Land: Irland
Zusätzliche Informationen: 0000
5.1.3.
Geschätzte Dauer
Andere Laufzeit: Unbekannt
5.1.4.
Verlängerung
Maximale Verlängerungen: 0
5.1.6.
Allgemeine Informationen
Vorbehaltene Teilnahme:
Teilnahme ist nicht vorbehalten.
Auftragsvergabeprojekt nicht aus EU-Mitteln finanziert
Die Beschaffung fällt unter das Übereinkommen über das öffentliche Beschaffungswesen: ja
5.1.9.
Eignungskriterien
Quellen der Eignungskriterien: Auftragsunterlagen
5.1.11.
Auftragsunterlagen
Sprachen, in denen die Auftragsunterlagen offiziell verfügbar sind: Englisch
Sprachen, in denen die Auftragsunterlagen (oder Teile davon) offiziell verfügbar sind: Englisch
5.1.12.
Bedingungen für die Auftragsvergabe
Bedingungen für die Einreichung:
Elektronische Einreichung: Erforderlich
Sprachen, in denen Angebote oder Teilnahmeanträge eingereicht werden können: Englisch
Frist für den Eingang der Teilnahmeanträge: 29/08/2027 15:00:00 (UTC+01:00) Mitteleuropäische Zeit, Westeuropäische Sommerzeit
Auftragsbedingungen:
Die Auftragsausführung muss im Rahmen von Programmen für geschützte Beschäftigungsverhältnisse erfolgen: Nein
5.1.16.
Weitere Informationen, Schlichtung und Nachprüfung
Überprüfungsstelle: The High Court of Ireland
Organisation, die zusätzliche Informationen über das Vergabeverfahren bereitstellt: Bus Eireann/Irish Bus
Organisation, die einen Offline-Zugang zu den Vergabeunterlagen bereitstellt: Bus Eireann/Irish Bus
Organisation, die weitere Informationen für die Nachprüfungsverfahren bereitstellt: The High Court of Ireland
Organisation, die Teilnahmeanträge entgegennimmt: Bus Eireann/Irish Bus
Organisation, die Angebote bearbeitet: Bus Eireann/Irish Bus
8. Organisationen
8.1.
ORG-0001
Offizielle Bezeichnung: Bus Eireann/Irish Bus
Registrierungsnummer: 119570
Postanschrift: 21 Phibsboro Road, Dublin 7
Stadt: Dublin
Postleitzahl: D07X2AE
Land, Gliederung (NUTS): Dublin (IE061)
Land: Irland
Telefon: 01 7033412
Rollen dieser Organisation:
Beschaffer
Organisation, die zusätzliche Informationen über das Vergabeverfahren bereitstellt
Organisation, die einen Offline-Zugang zu den Vergabeunterlagen bereitstellt
Organisation, die Teilnahmeanträge entgegennimmt
Organisation, die Angebote bearbeitet
8.1.
ORG-0002
Offizielle Bezeichnung: The High Court of Ireland
Registrierungsnummer: The High Court of Ireland
Abteilung: The High Court of Ireland
Postanschrift: Four Courts, Inns Quay, Dublin 7
Stadt: Dublin
Postleitzahl: D07 WDX8
Land, Gliederung (NUTS): Dublin (IE061)
Land: Irland
Telefon: +353 1 8886000
Rollen dieser Organisation:
Überprüfungsstelle
Organisation, die weitere Informationen für die Nachprüfungsverfahren bereitstellt
8.1.
ORG-0003
Offizielle Bezeichnung: European Dynamics S.A.
Registrierungsnummer: 002024901000
Abteilung: European Dynamics S.A.
Stadt: Athens
Postleitzahl: 15125
Land, Gliederung (NUTS): Βόρειος Τομέας Αθηνών (EL301)
Land: Griechenland
Telefon: +30 2108094500
Rollen dieser Organisation:
TED eSender
Kennung/Fassung der Bekanntmachung: 0fc60071-0264-425b-8c71-db02dce65f28 - 01
Formulartyp: Wettbewerb
Art der Bekanntmachung: Bekanntmachung über das Bestehen eines Prüfungssystems
Unterart der Bekanntmachung: 15
Datum der Übermittlung der Bekanntmachung: 28/08/2026 13:01:27 (UTC+01:00) Mitteleuropäische Zeit, Westeuropäische Sommerzeit
Sprachen, in denen diese Bekanntmachung offiziell verfügbar ist: Englisch
Veröffentlichungsnummer der Bekanntmachung: 597281-2026
ABl. S – Nummer der Ausgabe: 167/2026
Datum der Veröffentlichung: 31/08/2026