1. Buyer
1.1.
Buyer
Official name: Commissione europea, Centro comune di ricerca (JRC)
Legal type of the buyer: EU institution, body or agency
Activity of the contracting authority: General public services
2. Procedure
2.1.
Procedure
Title: Rinnovo, ristrutturazione, costruzione, manutenzione ordinaria e straordinaria degli impianti idrosanitari, termici, di gas e di scarico del sito JRC di Ispra (VA)
Description: Si tratta di una gara d'appalto ricorrente per le opere idrauliche e igienico-sanitarie e per altri lavori termoidraulici di costruzione realizzati nel sito. Rientrano nel presente contratto anche la manutenzione di riscaldamento, gas, impianti idraulici, impianti igienico-sanitari e altri lavori pertinenti.
Procedure identifier: c7cf8cf5-f36b-401d-acc2-ac7aa744c27e
Internal identifier: EC-JRC/IPR/2026/OP/0342
Type of procedure: Open
The procedure is accelerated: no
2.1.1.
Purpose
Main nature of the contract: Works
Main classification (cpv): 45330000 Plumbing and sanitary works
2.1.2.
Place of performance
Country: Italy
Anywhere in the given country
Additional information: Si invita a consultare i documenti di gara.
2.1.3.
Value
Estimated value excluding VAT: 3 500 000,00 EUR
2.1.4.
General information
Additional information: In caso di indisponibilità o di perturbazioni nel funzionamento dei mezzi di comunicazione elettronici di cui alla sezione 5.1.11 nei 5 giorni di calendario precedenti il termine di ricezione indicato alla sezione 5.1.12, l'amministrazione aggiudicatrice si riserva il diritto di prorogare tale termine e di rendere pubblica tale proroga all'indirizzo Internet di cui alla sezione 5.1.11, senza previa pubblicazione di una rettifica del presente avviso. Gli operatori economici interessati a questo appalto sono invitati a iscriversi alla gara d'appalto all'indirizzo di cui alla sezione 5.1.11., in modo da essere informati della pubblicazione di nuovi documenti o informazioni.
Legal basis:
Regulation (EU, Euratom) 2024/2509
2.1.6.
Grounds for exclusion
Sources of grounds for exclusion: Procurement Document
5. Lot
5.1.
Lot: LOT-0001
Title: Rinnovo, ristrutturazione, costruzione, manutenzione ordinaria e straordinaria degli impianti idrosanitari, termici, di gas e di scarico del sito JRC di Ispra (VA)
Description: Si tratta di una gara d'appalto ricorrente per le opere idrauliche e igienico-sanitarie e per altri lavori termoidraulici di costruzione realizzati nel sito. Rientrano nel presente contratto anche la manutenzione di riscaldamento, gas, impianti idraulici, impianti igienico-sanitari e altri lavori pertinenti.
Internal identifier: EC-JRC/IPR/2026/OP/0342
5.1.1.
Purpose
Main nature of the contract: Works
Main classification (cpv): 45330000 Plumbing and sanitary works
Additional classification (cpv): 44115200 Plumbing and heating materials, 44410000 Articles for the bathroom and kitchen, 45231223 Gas distribution ancillary work, 50700000 Repair and maintenance services of building installations, 44160000 Pipeline, piping, pipes, casing, tubing and related items, 44600000 Tanks, reservoirs and containers; central-heating radiators and boilers, 50500000 Repair and maintenance services for pumps, valves, taps and metal containers and machinery
5.1.2.
Place of performance
Country: Italy
Anywhere in the given country
Additional information: Si invita a consultare i documenti di gara.
5.1.3.
Estimated duration
Duration: 48 Months
5.1.4.
Renewal
Maximum renewals: 1
Other information about renewals: Il contratto quadro è concluso per un periodo iniziale di 24 (ventiquattro) mesi, rinnovabile 1 (uno) volte. Si prega di consultare il progetto di contratto quadro nei documenti di gara.
5.1.5.
Value
Estimated value excluding VAT: 3 500 000,00 EUR
5.1.6.
General information
Reserved participation:
Participation is not reserved.
Procurement Project fully or partially financed with EU Funds.
The procurement is covered by the Government Procurement Agreement (GPA): no
Information about previous notices:
Identifier of the previous notice: 131081-2026
5.1.9.
Selection criteria
Sources of selection criteria: Procurement Document
5.1.10.
Award criteria
Criterion:
Type: Quality
Description: Si invita a consultare i documenti di gara.
Category of award weight criterion: Weight (percentage, exact)
Award criterion number: 50
Criterion:
Type: Price
Description: Si invita a consultare i documenti di gara.
Category of award weight criterion: Weight (percentage, exact)
Award criterion number: 50
5.1.11.
Procurement documents
Deadline for requesting additional information: 19/06/2026 23:59:59 (UTC+02:00) Eastern European Time, Central European Summer Time
Ad hoc communication channel:
Name: Funding and Tenders Portal
5.1.12.
Terms of procurement
Terms of submission:
Electronic submission: Required
Languages in which tenders or requests to participate may be submitted: Bulgarian, Czech, Danish, German, Greek, English, Spanish, Estonian, Finnish, French, Irish, Croatian, Hungarian, Italian, Lithuanian, Latvian, Maltese, Dutch, Polish, Portuguese, Romanian, Slovak, Slovenian, Swedish
Electronic catalogue: Not allowed
Deadline for receipt of tenders: 29/06/2026 16:00:59 (UTC+02:00) Eastern European Time, Central European Summer Time
Duration during which the tender must remain valid: 6 Months
Information about public opening:
Opening date: 30/06/2026 10:00:00 (UTC+02:00) Eastern European Time, Central European Summer Time
Terms of contract:
The execution of the contract must be performed within the framework of sheltered employment programmes: No
Electronic invoicing: Allowed
Electronic ordering will be used: yes
Electronic payment will be used: yes
5.1.15.
Techniques
Framework agreement:
Framework agreement, without reopening of competition
Maximum number of participants: 1
Information about the dynamic purchasing system:
No dynamic purchase system
5.1.16.
Further information, mediation and review
Review organisation: LA CORTE DI GIUSTIZIA DELL’UNIONE EUROPEA - Tribunale
Organisation providing more information on the review procedures: Commissione europea, Centro comune di ricerca (JRC)
8. Organisations
8.1.
ORG-0001
Official name: Commissione europea, Centro comune di ricerca (JRC)
Registration number: COM
Department: JRC.R - Operations and Support Management
Postal address: Via Enrico Fermi 2749
Town: Ispra (VA)
Postcode: I-21027
Country subdivision (NUTS): Varese (ITC41)
Country: Italy
Telephone: +32 2 299 11 11
Roles of this organisation:
Buyer
Organisation providing more information on the review procedures
8.1.
ORG-0002
Official name: LA CORTE DI GIUSTIZIA DELL’UNIONE EUROPEA - Tribunale
Registration number: CURIA
Postal address: Rue du Fort Niedergrünewald
Town: Luxembourg
Postcode: L-2925
Country subdivision (NUTS): Luxembourg (LU000)
Country: Luxembourg
Telephone: +352 4303-1
Roles of this organisation:
Review organisation
8.1.
ORG-0003
Official name: Commissione europea
Registration number: EUCOM
Postal address: Mondrian (CDMA), Rue du Champ de Mars 21
Town: Brussels
Postcode: B-1050
Country subdivision (NUTS): Arr. de Bruxelles-Capitale/Arr. Brussel-Hoofdstad (BE100)
Country: Belgium
Telephone: +32 2 299 11 11
Roles of this organisation:
TED eSender
Notice identifier/version: c02ebac8-9521-40e9-97c0-0446078d34d9 - 01
Form type: Competition
Notice type: Contract or concession notice – standard regime
Notice subtype: 16
Notice dispatch date: 13/05/2026 14:57:30 (UTC+02:00) Eastern European Time, Central European Summer Time
Languages in which this notice is officially available: Italian
Notice publication number: 331649-2026
OJ S issue number: 93/2026
Publication date: 15/05/2026