1. Buyer
1.1.
Buyer
Official name: Lille Métropole Habitat
Legal type of the buyer: Body governed by public law
Activity of the contracting authority: Housing and community amenities
2. Procedure
2.1.
Procedure
Title: Accord-cadre de travaux à marchés subséquents pour la rénovation des installations CVC
Description: Acheteur LILLE METROPOLE HABITAT Type de contrat Accord-cadre à marchés subséquents multi-attributaires sans minimum et avec maximum de 20 000 000 euro(s) HT Structure Lot unique (3 attributaires maximum) Lieu d'exécution Métropole Lilloise Durée 24 mois renouvelable 1 fois 24 mois soit 48 mois maximum Variation des prix Révisables Nature des prix Prix unitaires Pénalités de retard Se référer au CCAP
Procedure identifier: c3dac7d8-0883-4250-a2cb-f64e5bf1c8ed
Internal identifier: 25S0074
Type of procedure: Open
The procedure is accelerated: no
2.1.1.
Purpose
Main nature of the contract: Works
Main classification (cpv): 45330000 Plumbing and sanitary works
Additional classification (cpv): 44162000 Piping, 45331000 Heating, ventilation and air-conditioning installation work
2.1.2.
Place of performance
Postal address: 425 Boulevard Gambetta
Town: Tourcoing
Postcode: 59200
Country subdivision (NUTS): Nord (FRE11)
Country: France
2.1.4.
General information
Legal basis:
Directive 2014/24/EU
2.1.6.
Grounds for exclusion
Sources of grounds for exclusion: Procurement Document
5. Lot
5.1.
Lot: LOT-0000
Title: Accord-cadre de travaux à marchés subséquents pour la rénovation des installations CVC
Description: Acheteur LILLE METROPOLE HABITAT Type de contrat Accord-cadre à marchés subséquents multi-attributaires sans minimum et avec maximum de 20 000 000 euro(s) HT Structure Lot unique (3 attributaires maximum) Lieu d'exécution Métropole Lilloise Durée 24 mois renouvelable 1 fois 24 mois soit 48 mois maximum Variation des prix Révisables Nature des prix Prix unitaires Pénalités de retard Se référer au CCAP
Internal identifier: T-PF-1834133
5.1.1.
Purpose
Main nature of the contract: Works
Main classification (cpv): 45330000 Plumbing and sanitary works
Additional classification (cpv): 44162000 Piping, 45331000 Heating, ventilation and air-conditioning installation work
5.1.2.
Place of performance
Postal address: 425 Boulevard Gambetta
Town: Tourcoing
Postcode: 59200
Country subdivision (NUTS): Nord (FRE11)
Country: France
5.1.3.
Estimated duration
Start date: 10/08/2026
Duration: 48 Months
5.1.4.
Renewal
Maximum renewals: 1
Other information about renewals: Nombre de reconductions : 1 Durée de chaque reconduction : 24 mois Durée maximale du contrat : 48 mois
5.1.6.
General information
This is a recurrent procurement
Description: Début d'exécution : à compter de la notification. Période initiale : 24 mois. Reconduction tacite : 1 fois pour une période de 24 mois. Durée maximale de l'accord-cadre : 48 mois
Reserved participation:
Participation is not reserved.
Procurement Project not financed with EU Funds.
The procurement is covered by the Government Procurement Agreement (GPA): no
5.1.9.
Selection criteria
Sources of selection criteria: Procurement Document
5.1.11.
Procurement documents
Ad hoc communication channel:
Name: AW Solutions
5.1.12.
Terms of procurement
Terms of submission:
Electronic submission: Required
Languages in which tenders or requests to participate may be submitted: French
Electronic catalogue: Not allowed
Deadline for receipt of tenders: 10/07/2026 12:00:00 (UTC+02:00) Eastern European Time, Central European Summer Time
Duration during which the tender must remain valid: 4 Months
Information about public opening:
Opening date: 10/07/2026 12:10:00 (UTC+02:00) Eastern European Time, Central European Summer Time
Place: Lille Metropole Habitat
Terms of contract:
The execution of the contract must be performed within the framework of sheltered employment programmes: No
Electronic invoicing: Required
Electronic ordering will be used: no
Electronic payment will be used: no
5.1.15.
Techniques
Framework agreement:
Framework agreement, with reopening of competition
Maximum number of participants: 1
Information about the dynamic purchasing system:
No dynamic purchase system
5.1.16.
Further information, mediation and review
Review organisation: Tribunal administratif de Lille
Information about review deadlines: Les délais et voies de recours sont les suivants : - référé précontractuel jusqu'à la signature du contrat conformément à l'article L551.1 et suivants du code de justice administrative. - référé contractuel à compter de la signature du marché public et dans un délai de 31 jours suivants la publication de l'avis d'attribution conformément à l'article L551-13 et suivants du CJA. - recours en contestation de la validité du marché public, conformément à l'arrêt du Conseil d'Etat du 4 avril 2014 "Tarn et Garonne" dans un délai de 2 mois à compter de la publication de l'avis d'attribution. Le tribunal compétent est le suivant : Tribunal Administratif de Lille 5 Rue Geoffroy Saint-Hilaire - CS 62039 59014 Lille
8. Organisations
8.1.
ORG-0001
Official name: Avenue-Web Systèmes
Registration number: F2B5058D-D94E-0BC6-73C7BC61077AFEE5
Town: Seyssinet-Pariset
Postcode: 38170
Country subdivision (NUTS): Isère (FRK24)
Country: France
Telephone: +33480041260
Roles of this organisation:
TED eSender
8.1.
ORG-0002
Official name: Lille Métropole Habitat
Registration number: 54964
Postal address: 425 Boulevard Gambetta
Town: Tourcoing
Postcode: 59200
Country subdivision (NUTS): Nord (FRE11)
Country: France
Contact point: BITTER Maxime
Telephone: 0970249249
Roles of this organisation:
Buyer
8.1.
ORG-0003
Official name: Tribunal administratif de Lille
Registration number: F2B505CB-9A9E-E088-84E16FB131822E38
Postal address: 143, rue Jacquemars Giélée
Town: Lille
Postcode: 59014
Country subdivision (NUTS): Nord (FRE11)
Country: France
Telephone: 0320631300
Fax: 0320631347
Roles of this organisation:
Review organisation
Notice identifier/version: 5417a678-a6d8-41d9-b27e-c3c67b922784 - 01
Form type: Competition
Notice type: Contract or concession notice – standard regime
Notice subtype: 16
Notice dispatch date: 10/06/2026 16:10:35 (UTC+02:00) Eastern European Time, Central European Summer Time
Languages in which this notice is officially available: French
Notice publication number: 402833-2026
OJ S issue number: 112/2026
Publication date: 12/06/2026