1. Buyer
1.1.
Buyer
Official name: Presidencia del Instituto Insular de Atención Social y Sociosanitaria - IASS
Legal type of the buyer: Local authority
Activity of the contracting authority: Social protection
2. Procedure
2.1.
Procedure
Title: La ejecución de las obras comprendidas en el proyecto denominado Proyecto de finalización de las obras necesarias para la terminación del nuevo del NUEVO CAMP LA CUESTA redactado por la empresa AJAH ARQUITECTOS, S.L.P. con la finalidad de terminar el Nuevo Centro - CAMP “La Cuesta”
Description: Este contrato de obra trae causa de un primer contrato administrativo de obra para la ejecución del "Proyecto modificado del Proyecto de ejecución del CAMP LA CUESTA", adjudicado en diciembre de 2023, y finalmente resuelto por el órgano de contratación, por causa imputable al contratista debido al bajo ritmo de ejecución de la obra. El proyecto ha sido objeto de actualización y se aprueba de forma definitiva por el órgano de contratación el "PROYECTO DE FINALIZACIÓN DEL CAMP LA CUESTA", cuya ejecución es el objeto de la presente licitación.
Procedure identifier: 5a6ab469-8775-44a8-ab63-19e73cf6de08
Internal identifier: CONT184/2026
Type of procedure: Open
The procedure is accelerated: no
2.1.1.
Purpose
Main nature of the contract: Works
Main classification (cpv): 45000000 Construction work
Additional classification (cpv): 45215000 Construction work for buildings relating to health and social services, for crematoriums and public conveniences
2.1.2.
Place of performance
Country subdivision (NUTS): Tenerife (ES709)
Country: Spain
2.1.3.
Value
Estimated value excluding VAT: 9 645 636,35 EUR
2.1.4.
General information
Legal basis:
Directive 2014/24/EU
2.1.6.
Grounds for exclusion
Sources of grounds for exclusion: Notice
Breaching of obligations set under purely national exclusion grounds: Motivos de exclusión exclusivamente nacionales
5. Lot
5.1.
Lot: LOT-0000
Title: La ejecución de las obras comprendidas en el proyecto denominado Proyecto de finalización de las obras necesarias para la terminación del nuevo del NUEVO CAMP LA CUESTA redactado por la empresa AJAH ARQUITECTOS, S.L.P. con la finalidad de terminar el Nuevo Centro - CAMP “La Cuesta”
Description: Este contrato de obra trae causa de un primer contrato administrativo de obra para la ejecución del "Proyecto modificado del Proyecto de ejecución del CAMP LA CUESTA", adjudicado en diciembre de 2023, y finalmente resuelto por el órgano de contratación, por causa imputable al contratista debido al bajo ritmo de ejecución de la obra. El proyecto ha sido objeto de actualización y se aprueba de forma definitiva por el órgano de contratación el "PROYECTO DE FINALIZACIÓN DEL CAMP LA CUESTA", cuya ejecución es el objeto de la presente licitación.
Internal identifier: CONT184/2026
5.1.1.
Purpose
Main nature of the contract: Works
Main classification (cpv): 45000000 Construction work
Additional classification (cpv): 45215000 Construction work for buildings relating to health and social services, for crematoriums and public conveniences
Options:
Description of the options: Ampliación del plazo de ejecución: Cuando se produzca un retraso en la ejecución de la obra por motivos no imputables al contratista y éste ofreciera cumplir sus compromisos, el órgano de contratación podrá ampliar el plazo inicialmente concedido, de conformidad con lo estipulado en la cláusula 9.3 del PCAP.
5.1.2.
Place of performance
Country subdivision (NUTS): Tenerife (ES709)
Country: Spain
5.1.3.
Estimated duration
Duration: 18 Months
5.1.4.
Renewal
Maximum renewals: 0
5.1.6.
General information
Reserved participation:
Participation is not reserved.
Procurement Project not financed with EU Funds.
The procurement is covered by the Government Procurement Agreement (GPA): no
5.1.9.
Selection criteria
Sources of selection criteria: Notice
Criterion: General yearly turnover
Description of selection criterion: Cifra anual de negocio
Criterion: References on specified works
Description of selection criterion: Trabajos realizados
Criterion: Technicians or technical bodies to carry out the work
Description of selection criterion: Técnicos o unidades técnicas
5.1.10.
Award criteria
Criterion:
Type: Price
Description: C.1. CRITERIO ECONÓMICO.
Category of award weight criterion: Weight (points, exact)
Award criterion number: 25
Criterion:
Type: Quality
Description: C.2. MEJORAS TÉCNICAS. IMPLANTACIÓN BIM EN LA OBRA.
Category of award weight criterion: Weight (points, exact)
Award criterion number: 30
Criterion:
Type: Quality
Description: C.3. EXPERIENCIA AÑADIDA AL EQUIPO TÉCNICO.
Category of award weight criterion: Weight (points, exact)
Award criterion number: 20
Criterion:
Type: Quality
Description: C.4. CRITERIOS MEDIOAMBIENTALES. HUELLA DE CARBONO.
Category of award weight criterion: Weight (points, exact)
Award criterion number: 15
Criterion:
Type: Quality
Description: C.5. CLÁUSULAS SOCIALES. MENOR SINIESTRALIDAD.
Category of award weight criterion: Weight (points, exact)
Award criterion number: 10
5.1.11.
Procurement documents
5.1.12.
Terms of procurement
Terms of submission:
Electronic submission: Required
Languages in which tenders or requests to participate may be submitted: Spanish
Electronic catalogue: Not allowed
Deadline for receipt of tenders: 21/08/2026 23:59:00 (UTC+02:00) Eastern European Time, Central European Summer Time
Duration during which the tender must remain valid: 1 Year
Information about public opening:
Opening date: 24/08/2026 09:00:00 (UTC+02:00) Eastern European Time, Central European Summer Time
Place: IASS
Terms of contract:
The execution of the contract must be performed within the framework of sheltered employment programmes: No
Conditions relating to the performance of the contract: Sometimiento del contratista a la normativa de protección de datos.
Electronic invoicing: Allowed
Electronic ordering will be used: no
Electronic payment will be used: yes
5.1.15.
Techniques
Framework agreement:
No framework agreement
Information about the dynamic purchasing system:
No dynamic purchase system
5.1.16.
Further information, mediation and review
Review organisation: Presidencia del Instituto Insular de Atención Social y Sociosanitaria - IASS - Tribunal Administrativo de Contratos Públicos de la Comunidad Autónoma de Canarias
Information about review deadlines: Contra las actuaciones previstas en el artículo 44 de la LCSP podrá interponerse Recurso Especial en materia de contratación ante el Tribunal Administrativo de Contratos Públicos de la Comunidad Autónoma de Canarias en el plazo de 15 días hábiles.
8. Organisations
8.1.
ORG-0001
Official name: Presidencia del Instituto Insular de Atención Social y Sociosanitaria - IASS
Registration number: 31055010149261
Registration number: Q3800402D
Town: Santa Cruz de Tenerife
Postcode: 38003
Country subdivision (NUTS): Tenerife (ES709)
Country: Spain
Contact point: Presidencia del Instituto Insular de Atención Social y Sociosanitaria - IASS
Telephone: 922843200
Other contact points:
Official name: Tribunal Administrativo de Contratos Públicos de la Comunidad Autónoma de Canarias
Town: Santa Cruz de Tenerife
Postcode: 38003
Country subdivision (NUTS): Tenerife (ES709)
Country: Spain
Roles of this organisation:
Buyer
Review organisation
Notice identifier/version: 3a157ccb-8e6d-47b1-afde-d5ce908157d0 - 01
Form type: Competition
Notice type: Contract or concession notice – standard regime
Notice subtype: 16
Notice dispatch date: 23/07/2026 14:59:44 (UTC+02:00) Eastern European Time, Central European Summer Time
Languages in which this notice is officially available: Spanish
Notice publication number: 514125-2026
OJ S issue number: 141/2026
Publication date: 24/07/2026