1. Nabywca
1.1.
Nabywca
Oficjalna nazwa: Rásaíocht Con Éireann
Status prawny nabywcy: Podmiot prawa publicznego kontrolowany przez instytucję administracji centralnej
Sektor działalności instytucji zamawiającej: Organizacja wypoczynku, kultura i religia
2. Procedura
2.1.
Procedura
Tytuł: Refurbishment and improvement works at Curraheen Park Greyhound Stadium
Opis: Greyhound Racing Ireland ("the Employer") invites suitably qualified and experienced Contractors to submit a Tender for the execution and completion of refurbishment and improvement works at Curraheen Park Greyhound Stadium, together with all associated works as described within the Tender Documents. The Works comprise the refurbishment and upgrading of identified areas within Curraheen Park Greyhound Stadium, including associated building, architectural, mechanical and electrical works, finishes, fittings and all ancillary works necessary to complete the project in accordance with the Contract Documents. The principal elements of the Works include, but are not limited to, refurbishment of public circulation areas, bars, restaurants, corporate hospitality suites, sanitary accommodation, stairways and back-of-house areas, together with the formation of new wind lobbies, associated signage, floor, wall and ceiling finishes, joinery refurbishment, decoration and all associated making good. The Works are required to be undertaken within a live greyhound racing venue and are subject to critical operational milestones associated with the 2026 Laurels competition. Tenderers shall satisfy themselves that the proposed Works can be executed within the programme constraints set out in the Tender Documents, including the requirement to complete the Phase 1 Works by 11 September 2026 to facilitate operational readiness prior to the commencement of the Laurels. Tenderers are invited to submit a competitive Tender based upon the requirements set out within the Tender Package and in accordance with the Public Works Contract identified therein.
Identyfikator procedury: f6609e76-2194-4c1b-9a3f-f4893c1bc808
Rodzaj procedury: Otwarta
Procedura jest przyspieszona: nie
2.1.1.
Przeznaczenie
Charakter zamówienia: Roboty budowlane
Główna klasyfikacja (cpv): 45210000 Roboty budowlane w zakresie budynków
Dodatkowa klasyfikacja (cpv): 45262700 Przebudowa budynków
2.1.2.
Miejsce realizacji
Podpodział krajowy (NUTS): A Coruña (ES111)
Kraj: Irlandia
2.1.3.
Wartość
Szacunkowa wartość bez VAT: 1,00 EUR
2.1.4.
Informacje ogólne
Podstawa prawna:
Dyrektywa 2014/24/UE
2.1.6.
Podstawy wykluczenia
Powody wykluczenia źródła: Dokumenty zamówienia
5. Część zamówienia
5.1.
Część zamówienia: LOT-0001
Tytuł: Refurbishment and improvement works at Curraheen Park Greyhound Stadium
Opis: Greyhound Racing Ireland ("the Employer") invites suitably qualified and experienced Contractors to submit a Tender for the execution and completion of refurbishment and improvement works at Curraheen Park Greyhound Stadium, together with all associated works as described within the Tender Documents. The Works comprise the refurbishment and upgrading of identified areas within Curraheen Park Greyhound Stadium, including associated building, architectural, mechanical and electrical works, finishes, fittings and all ancillary works necessary to complete the project in accordance with the Contract Documents. The principal elements of the Works include, but are not limited to, refurbishment of public circulation areas, bars, restaurants, corporate hospitality suites, sanitary accommodation, stairways and back-of-house areas, together with the formation of new wind lobbies, associated signage, floor, wall and ceiling finishes, joinery refurbishment, decoration and all associated making good. The Works are required to be undertaken within a live greyhound racing venue and are subject to critical operational milestones associated with the 2026 Laurels competition. Tenderers shall satisfy themselves that the proposed Works can be executed within the programme constraints set out in the Tender Documents, including the requirement to complete the Phase 1 Works by 11 September 2026 to facilitate operational readiness prior to the commencement of the Laurels. Tenderers are invited to submit a competitive Tender based upon the requirements set out within the Tender Package and in accordance with the Public Works Contract identified therein.
Wewnętrzny identyfikator: 0
5.1.1.
Przeznaczenie
Charakter zamówienia: Roboty budowlane
Główna klasyfikacja (cpv): 45210000 Roboty budowlane w zakresie budynków
Dodatkowa klasyfikacja (cpv): 45262700 Przebudowa budynków
5.1.2.
Miejsce realizacji
Podpodział krajowy (NUTS): A Coruña (ES111)
Kraj: Irlandia
5.1.3.
Szacowany okres obowiązywania
Okres obowiązywania: 12 Miesiące
5.1.5.
Wartość
Szacunkowa wartość bez VAT: 1,00 EUR
5.1.6.
Informacje ogólne
Zastrzeżony udział:
Udział nie jest zastrzeżony.
Projekt zamówienia niefinansowany z funduszy UE
Zamówienie jest objęte zakresem Porozumienia w sprawie zamówień rządowych (GPA): tak
5.1.7.
Zamówienia strategiczne
Cel zamówienia strategicznego: Zamówienia inne niż strategiczne
5.1.9.
Kryteria kwalifikacji
Źródła kryteriów wyboru: Dokumenty zamówienia
5.1.11.
Dokumenty zamówienia
Języki, w których dokumenty zamówienia są oficjalnie dostępne: angielski
Języki, w których dokumenty zamówienia (lub ich części) są nieoficjalnie dostępne: angielski
Termin występowania z wnioskiem o dodatkowe informacje: 03/07/2026 13:00:00 (UTC+01:00) czas środkowoeuropejski, czas zachodnioeuropejski letni
5.1.12.
Warunki udzielenia zamówienia
Warunki zgłoszenia:
Zgłoszenie elektroniczne: Wymagane
Języki, w których można składać oferty lub wnioski o dopuszczenie do udziału: angielski
Katalog elektroniczny: Niedozwolone
Oferenci mogą złożyć więcej niż jedną ofertę: Niedozwolone
Termin składania ofert: 10/07/2026 13:00:00 (UTC+01:00) czas środkowoeuropejski, czas zachodnioeuropejski letni
Okres, przez który oferta musi pozostać ważna: 180 Dni
Informacje na temat publicznego otwarcia:
Data otwarcia: 10/07/2026 13:30:00 (UTC+01:00) czas środkowoeuropejski, czas zachodnioeuropejski letni
Warunki zamówienia:
Wykonanie zamówienia musi odbywać się w ramach programów zatrudnienia chronionego: Nie
Fakturowanie elektroniczne: Dozwolone
Stosowane będą zlecenia elektroniczne: tak
Stosowane będą płatności elektroniczne: tak
5.1.15.
Techniki
Umowa ramowa:
Brak umowy ramowej
Informacje o dynamicznym systemie zakupów:
Brak dynamicznego systemu zakupów
5.1.16.
Dalsze informacje, mediacja i odwołanie
Organ odwoławczy: The High Court of Ireland
Organizacja zapewniająca dostęp offline do dokumentów zamówienia: Rásaíocht Con Éireann
Organizacja udzielająca dodatkowych informacji na temat procedur odwoławczych: The High Court of Ireland
Organizacja przyjmująca wnioski o dopuszczenie do udziału: Rásaíocht Con Éireann
Organizacja rozpatrująca oferty: Rásaíocht Con Éireann
8. Organizacje
8.1.
ORG-0001
Oficjalna nazwa: Rásaíocht Con Éireann
Numer rejestracyjny: 0532995u
Adres pocztowy: Greenpark,Dock Road
Miejscowość: Limerick
Kod pocztowy: v94y17x
Podpodział krajowy (NUTS): Mid-West (IE051)
Kraj: Irlandia
Telefon: 061448000
Role tej organizacji:
Nabywca
Organizacja zapewniająca dostęp offline do dokumentów zamówienia
Organizacja przyjmująca wnioski o dopuszczenie do udziału
Organizacja rozpatrująca oferty
8.1.
ORG-0002
Oficjalna nazwa: The High Court of Ireland
Numer rejestracyjny: The High Court of Ireland
Departament: The High Court of Ireland
Adres pocztowy: Four Courts, Inns Quay, Dublin 7
Miejscowość: Dublin
Kod pocztowy: D07 WDX8
Podpodział krajowy (NUTS): Dublin (IE061)
Kraj: Irlandia
Telefon: +353 1 8886000
Role tej organizacji:
Organ odwoławczy
Organizacja udzielająca dodatkowych informacji na temat procedur odwoławczych
8.1.
ORG-0003
Oficjalna nazwa: European Dynamics S.A.
Numer rejestracyjny: 002024901000
Departament: European Dynamics S.A.
Miejscowość: Athens
Kod pocztowy: 15125
Podpodział krajowy (NUTS): Βόρειος Τομέας Αθηνών (EL301)
Kraj: Grecja
Telefon: +30 2108094500
Role tej organizacji:
TED eSender
Identyfikator/wersja ogłoszenia: 3b37fbd4-6a64-4833-9cbc-1ca90ac7f3dd - 01
Typ formularza: Procedura konkurencyjna
Rodzaj ogłoszenia: Ogłoszenie o zamówieniu lub ogłoszenie o koncesji – tryb standardowy
Podrodzaj ogłoszenia: 16
Ogłoszenie – data wysłania: 15/06/2026 18:10:27 (UTC+01:00) czas środkowoeuropejski, czas zachodnioeuropejski letni
Języki, w których przedmiotowe ogłoszenie jest oficjalnie dostępne: angielski
Numer publikacji ogłoszenia: 413551-2026
Numer wydania Dz.U. S: 115/2026
Data publikacji: 17/06/2026