1. Upphandlare
1.1.
Upphandlare
Officiellt namn: Rásaíocht Con Éireann
Köparens rättsliga status: Offentligt styrt organ som kontrolleras av en statlig myndighet
Den upphandlande myndighetens verksamhet: Fritidsverksamhet, kultur och religion
2. Förfarande
2.1.
Förfarande
Titel: Refurbishment and improvement works at Curraheen Park Greyhound Stadium
Beskrivning: Greyhound Racing Ireland ("the Employer") invites suitably qualified and experienced Contractors to submit a Tender for the execution and completion of refurbishment and improvement works at Curraheen Park Greyhound Stadium, together with all associated works as described within the Tender Documents. The Works comprise the refurbishment and upgrading of identified areas within Curraheen Park Greyhound Stadium, including associated building, architectural, mechanical and electrical works, finishes, fittings and all ancillary works necessary to complete the project in accordance with the Contract Documents. The principal elements of the Works include, but are not limited to, refurbishment of public circulation areas, bars, restaurants, corporate hospitality suites, sanitary accommodation, stairways and back-of-house areas, together with the formation of new wind lobbies, associated signage, floor, wall and ceiling finishes, joinery refurbishment, decoration and all associated making good. The Works are required to be undertaken within a live greyhound racing venue and are subject to critical operational milestones associated with the 2026 Laurels competition. Tenderers shall satisfy themselves that the proposed Works can be executed within the programme constraints set out in the Tender Documents, including the requirement to complete the Phase 1 Works by 11 September 2026 to facilitate operational readiness prior to the commencement of the Laurels. Tenderers are invited to submit a competitive Tender based upon the requirements set out within the Tender Package and in accordance with the Public Works Contract identified therein.
Förfarandets identifierare: f6609e76-2194-4c1b-9a3f-f4893c1bc808
Typ av förfarande: Öppet
Förfarandet är påskyndat: nej
2.1.1.
Föremålet för upphandlingen
Kontraktets art: Byggentreprenader
Huvudklassificering (cpv): 45210000 Byggnadsanläggning
Ytterligare klassificering (cpv): 45262700 Ombyggnadsarbete
2.1.2.
Leveransplats
Del av land (NUTS): A Coruña (ES111)
Land: Irland
2.1.3.
Värde
Beräknat värde exklusive moms: 1,00 EUR
2.1.4.
Allmänna upplysningar
Rättslig grund:
Direktiv 2014/24/EU
2.1.6.
Uteslutningsgrunder
Källor till uteslutningsgrunder: Upphandlingsdokument
5. Del (anbudsområde)
5.1.
Del (anbudsområde): LOT-0001
Titel: Refurbishment and improvement works at Curraheen Park Greyhound Stadium
Beskrivning: Greyhound Racing Ireland ("the Employer") invites suitably qualified and experienced Contractors to submit a Tender for the execution and completion of refurbishment and improvement works at Curraheen Park Greyhound Stadium, together with all associated works as described within the Tender Documents. The Works comprise the refurbishment and upgrading of identified areas within Curraheen Park Greyhound Stadium, including associated building, architectural, mechanical and electrical works, finishes, fittings and all ancillary works necessary to complete the project in accordance with the Contract Documents. The principal elements of the Works include, but are not limited to, refurbishment of public circulation areas, bars, restaurants, corporate hospitality suites, sanitary accommodation, stairways and back-of-house areas, together with the formation of new wind lobbies, associated signage, floor, wall and ceiling finishes, joinery refurbishment, decoration and all associated making good. The Works are required to be undertaken within a live greyhound racing venue and are subject to critical operational milestones associated with the 2026 Laurels competition. Tenderers shall satisfy themselves that the proposed Works can be executed within the programme constraints set out in the Tender Documents, including the requirement to complete the Phase 1 Works by 11 September 2026 to facilitate operational readiness prior to the commencement of the Laurels. Tenderers are invited to submit a competitive Tender based upon the requirements set out within the Tender Package and in accordance with the Public Works Contract identified therein.
Intern identifierare: 0
5.1.1.
Föremålet för upphandlingen
Kontraktets art: Byggentreprenader
Huvudklassificering (cpv): 45210000 Byggnadsanläggning
Ytterligare klassificering (cpv): 45262700 Ombyggnadsarbete
5.1.2.
Leveransplats
Del av land (NUTS): A Coruña (ES111)
Land: Irland
5.1.3.
Uppskattad löptid
Varaktighet: 12 Månader
5.1.5.
Värde
Beräknat värde exklusive moms: 1,00 EUR
5.1.6.
Allmänna upplysningar
Reserverad upphandling:
Deltagande är inte reserverat.
Upphandlingsprojekt som inte finansieras med EU-medel
Upphandlingen omfattas av Världshandelsorganisationens avtal om offentlig upphandling, GPA: ja
5.1.7.
Strategisk upphandling
Syftet med strategisk upphandling: Det tas inte hänsyn till miljö, sociala aspekter eller innovation i upphandlingen
5.1.9.
Urvalskriterier
Källor till urvalskriterier: Upphandlingsdokument
5.1.11.
Upphandlingsdokument
Språk som upphandlingsdokumenten är officiellt tillgängliga på: engelska
Språk som upphandlingsdokumenten (eller delar av dem) är inofficiellt tillgängliga på: engelska
Sista dag för att begära kompletterande information: 03/07/2026 13:00:00 (UTC+01:00) Centraleuropeisk tid / västeuropeisk sommartid
5.1.12.
Upphandlingsvillkor
Villkor för inlämning:
Elektronisk inlämning: Krävs
De språk som kan användas i anbuden eller anbudsansökningarna: engelska
Elektronisk katalog: Ej tillåten
Anbudsgivare får lämna in fler än ett anbud: Ej tillåten
Tidsfrist för mottagande av anbud: 10/07/2026 13:00:00 (UTC+01:00) Centraleuropeisk tid / västeuropeisk sommartid
Varaktighet under vilken anbudet måste förbli giltigt: 180 Dagar
Information om offentlig anbudsöppning:
Öppningsdatum: 10/07/2026 13:30:00 (UTC+01:00) Centraleuropeisk tid / västeuropeisk sommartid
Kontraktsvillkor:
Kontraktet måste genomföras inom ramen för program för skyddad anställning: Nej
Elektronisk fakturering: Tillåten
Elektronisk beställning kommer att användas: ja
Elektronisk betalning kommer att användas: ja
5.1.15.
Metoder
Ramavtal:
Upphandlingen avser inte ett ramavtal
Information om det dynamiska inköpssystemet:
Upphandlingen avser inte ett dynamiskt inköpssystem
5.1.16.
Kompletterande information, medling och prövning
Prövningsorganisation: The High Court of Ireland
Organisation som ger offlineåtkomst till upphandlingsdokumenten: Rásaíocht Con Éireann
Organisation som ger mer information om prövningsförfaranden: The High Court of Ireland
Organisation som mottar anbudsansökningar: Rásaíocht Con Éireann
Organisation som behandlar anbud: Rásaíocht Con Éireann
8. Organisationer
8.1.
ORG-0001
Officiellt namn: Rásaíocht Con Éireann
Registreringsnummer: 0532995u
Postadress: Greenpark,Dock Road
Ort: Limerick
Postnummer: v94y17x
Del av land (NUTS): Mid-West (IE051)
Land: Irland
Tfn: 061448000
Den här organisationens roller:
Upphandlare
Organisation som ger offlineåtkomst till upphandlingsdokumenten
Organisation som mottar anbudsansökningar
Organisation som behandlar anbud
8.1.
ORG-0002
Officiellt namn: The High Court of Ireland
Registreringsnummer: The High Court of Ireland
Avdelning: The High Court of Ireland
Postadress: Four Courts, Inns Quay, Dublin 7
Ort: Dublin
Postnummer: D07 WDX8
Del av land (NUTS): Dublin (IE061)
Land: Irland
Tfn: +353 1 8886000
Den här organisationens roller:
Prövningsorganisation
Organisation som ger mer information om prövningsförfaranden
8.1.
ORG-0003
Officiellt namn: European Dynamics S.A.
Registreringsnummer: 002024901000
Avdelning: European Dynamics S.A.
Ort: Athens
Postnummer: 15125
Del av land (NUTS): Βόρειος Τομέας Αθηνών (EL301)
Land: Grekland
Tfn: +30 2108094500
Den här organisationens roller:
TED eSender
Identifierare/version för meddelandet: 3b37fbd4-6a64-4833-9cbc-1ca90ac7f3dd - 01
Formulärtyp: Konkurrensutsättning
Meddelandetyp: Meddelande om upphandling eller koncession – standardsystem
Meddelandets undertyp: 16
Avsändningsdatum för meddelandet: 15/06/2026 18:10:27 (UTC+01:00) Centraleuropeisk tid / västeuropeisk sommartid
Språk som det här meddelandet finns officiellt tillgängligt på: engelska
Meddelandets publiceringsnummer: 413551-2026
EUT S-nummer: 115/2026
Publiceringsdatum: 17/06/2026